General Terms and Conditions

1. The offer

Our offers are subject to change. Changes to the devices in response to technical development are reserved.
All technical documents shall remain the intellectual property of the contractor.

2. Prices

If between the dates the agreement is signed and the product is delivered materials costs increase on the basis of recommendations of the Joint Commission , or if there are changes in the global market prices for raw materials, or other costs or expenses beyond the contractor's control are incurred, then the prices shall be increased accordingly.
The prices are ex warehouse or ex works without packing, shipping, and distribution costs.

3. Performance times and dates

If the starting date of the delivery or the delivery itself is delayed or interrupted, then the agreed delivery periods shall be extended accordingly and he agreed completion dates postponed accordingly; if the delay or interruption is due to circumstances not under the control of the contractor, the customer shall bear all costs accrued by the delays or interruptions and may owe receivables to the contractor based on partial deliveries and invoices.
If the delay or interruption is due to circumstances not under the control of the contractor, the customer shall bear all costs accrued by the delays or interruptions and may owe receivables to the contractor based on partial deliveries and invoices.

4. Payments

All charges due to warnings and the costs of extra-judicial collection efforts by attorneys shall be borne by the customer.
If the customer is in default, the contractor is entitled to charge interest at a rate of at least 12% calculated annually, without affecting other claims for damages and higher
interest.
Payment can be arranged separately for each job

5. Transport and insurance
With the delivery of the goods ordered by you (post, rail, freight), we have fulfilled our contractual obligations and the risk is transferred to you.

6. Retention of ownership

All goods delivered, installed or otherwise handed over shall remain the property of the contractor until payment is received in full.
If the customer defaults on payment, the contractor shall be entitled to repossess the goods or make them unoperational, such action not constituting a rescission of the Agreement. The resulting costs will be borne by the customer.

7. Complaints

Obvious defects must be reported in writing within one week of receipt of goods; hidden defects must be reported in writing within one week after discovery of the defect.

8. Warranty

Unless the customer has asked for a product exchange, a free repair of the detected defects will be made by the deadline.
If a remedy is not possible or only with disproportionately high costs, a reasonable compensation shall be payable.
For small devices, a free warranty repair of the equipment shall be carried out in our factory.
Maximum guarantee period is 1 year from date of delivery. No further claims can be made.

9. Damages

The contractor shall be liable only for damages caused to the customer's property when such property was transferred to the contractor to fulfill the contract.
All other claims of the customer, especially those for the reimbursement of any additional damages, including consequential damages are excluded, unless the contractor is guilty of gross negligence or intentional harm.

10. Product liability

The equipment delivered and services performed only offer the level of safety that can be expected if licensing requirements, operating conditions and instructions, rules of the delivery system, etc. and any other information are followed.
In product liability cases, liability for property damage, including that of the contractor's suppliers and shippers, is limited to those damages suffered by consumers.
This limitation of liability is to be transferred to all recipients of the product with an obligation for further transfer.

11. Place of performance

The place of performance is contractor's headquarters.

12. Place of jurisdiction

Als Gerichtsstand wir Kreis- und Handelsgericht A-4910 Ried im Innkreis vereinbart. Österreichisches Recht gilt als vereinbart.